French
DeutschContractual provisions relating to time
Several terms and common clauses are used in contracts to refer to time, including usage in reference to the time at which, or the length of the period during which, a contracted activity is to be undertaken.
Time is of the essence
[edit]
"Time is of the essence" is a term used in contract law in England and Wales (a legal jurisdiction within the United Kingdom), Canada, Australia, New Zealand, other Commonwealth countries and the United States, expressing "the need for timely completion",[1] i.e. indicating that one or more parties to the agreement must perform by the time to which the parties have agreed if a delay will cause material harm. However, in the case of Foundation Development Corp. v. Loehmann's Inc. 788 P.2d 1189 (Arizona 1990), in which the lease included a Time is of the essence clause, the court ruled that a minor delay did not cause material harm and thus no breach of contract occurred.[2]
"Time is of the essence" may be contrasted with "reasonable time", where a delay in performing may be justified if it is reasonably required, based upon subjective circumstances such as unexpected weather,[1] and with the phrase time at large, which describes a situation where there is no date for completion, or where the date for completion has become invalid or unenforceable.[3] The contractor is then no longer bound by the obligation to complete the contract by a certain date.
"Time is of the essence" may also be contrasted with an "express condition", where a specific contract term must be performed to avoid breach, such as in the Court of Appeals of Indiana's decision in Dove v. Rose Acre Farms, Inc. 434 N.E.2d 931 (Ct. App. Ind. 1982).[4]
Time at large
[edit]"Time at large" is a common law principle [5] which can arise in four types of situation:
- where no time for performance has ever been agreed as part of the contract
- where a time which was fixed has ceased to apply, by agreement or an act which prevents its fulfillment, including an employer's act of prevention affecting completion
- where the employer has waived the right to insist on completion by the agreed date, or where the contractor is in breach of contract but the employer elects to continue with the contract on a delayed basis, or
- where the employer has failed to comply with the certification process, if this prevents the contract being administered correctly.[6]
The case of Holme v Guppy (1838) confirms the "prevention principle", which states that "if the party be prevented by the refusal of the other contracting party from completing the contract within the time limited he is not liable in law for the default".[7]
Where time is "at large", the contractor's obligation is to complete within a reasonable time. The facts of the case will determine what is a reasonable time.[6] Bellhouse and Cowan note that most forms of contract now have "adequate extension of time procedures", so it has become difficult to argue that an "at large" situation has arisen in most situations.[5]
"The principle in Bramall & Ogden" (referring to the case of Bramall & Ogden v Sheffield City Council (1983) 29 BLR 73)[8] established that confused legal drafting can give rise to a situation where time is "at large" due to the absence of agreement on contractual time for performance. In this case, Sheffield had contracted for the construction of 123 houses, which were completed on various dates. The contract provided for liquidated damages applicable on the number of houses incomplete, and stated a date for completion as 6 December 1976. The contract did not provide for sectional completion and the court held that the sectional basis on which the liquidated damages clause was to operate was inconsistent with the single end-date for anticipated completion, meaning that Sheffield were unable to enforce a damages claim for delay.[9][5]
"Time at large" arguments may also be utilised in a civil law context.[5]
Extension of time
[edit]Standard form contracts such as the Joint Contracts Tribunal (JCT) contract and the New Engineering Contract (NEC) family include various mechanisms for extending contracts to account for delay but still retain the need for the works to be completed by an agreed date.[10]
See also
[edit]References
[edit]- ^ a b Bryan A. Garner, ed. (2001). Black's Law Dictionary (2nd Pocket ed.). West Publishing Company. p. 584. ISBN 978-0314257918.
- ^ "Foundation Development Corp. v. Loehmann's, Inc". CaseBriefs. Retrieved May 9, 2015.
- ^ Law Insider, Time at large definition, accessed 9 December 2022
- ^ "Dove v. Rose Acre Farms, Inc". CaseBriefs. Retrieved May 9, 2015.
- ^ a b c d Bellhouse, J. and Cowan, P., Common Law “Time at Large” Arguments in a Civil Law Context, White & Case, LLP, 2008, accessed 20 December 2022
- ^ a b David Atkinson Ltd., Time at Large, published 2002, updated 8 April 2007, archived 7 April 2008, accessed 9 December 2022
- ^ 3 M&W 387, referred to in England and Wales Court of Appeal (Civil Division), North Midland Building Ltd v Cyden Homes Ltd., EWCA Civ 1744, paragraph 1, delivered 30 July 2018, accessed 9 December 2022
- ^ England and Wales High Court (Technology and Construction Court), Avoncroft Construction Ltd v Sharba Homes (CN) Ltd., [2008] EWHC 933 (TCC), delivered 29 April 2008, accessed 20 December 2022
- ^ RICS, Cases - Bramall & Ogden v Sheffield City Council, accessed 20 December 2022
- ^ Mendelle, J. and Raja, U., Extension of time - differing approaches under standard form construction contracts, Sharpe Pritchard, published 19 January 2017, accessed 28 September 2023
 | This legal term article is a stub. You can help Wikipedia by expanding it. |
  | This article relating to law in the United States or its constituent jurisdictions is a stub. You can help Wikipedia by expanding it. |
 | This article relating to law in the United Kingdom, or its constituent jurisdictions, is a stub. You can help Wikipedia by expanding it. |